Roofing Renovations for Jefferson County Courthouse
ID: IFB26021MR • State: Texas
Opportunity Assistant
Loading
Description
Background
The Jefferson County Purchasing Department is issuing an Invitation for Bids (IFB 26-021/MR) for roofing renovations at the Jefferson County Courthouse.
The purpose of this project is to enhance the structural integrity and aesthetic appeal of the courthouse, which serves as a vital facility for county operations.
The specifications for this project can be accessed through the Jefferson County website or by contacting The LaBiche Architectural Group, Inc.
Work Details
The contract involves comprehensive roofing renovations at the Jefferson County Courthouse.
Specific tasks include:
- Removal of existing roofing materials
- Installation of new roofing systems that meet current building codes and standards
- Ensuring proper insulation and waterproofing measures are implemented
- Compliance with all safety regulations during construction
- Provision of necessary documentation and warranties for materials used.
All work must adhere to the specifications outlined in the project manual provided by The LaBiche Architectural Group, Inc.
Period of Performance
The contract period will commence upon execution of the contract and is expected to be completed within a specified timeframe detailed in the bid documents.
The contractor must provide a schedule that outlines key milestones and completion dates.
Place of Performance
The work will be performed at the Jefferson County Courthouse located at 1149 Pearl Street, Beaumont, Texas 77701.
Bidder Requirements
Bidders are required to furnish a Bid Security amounting to five percent (5%) of the total contract cost.
A Performance Bond must be provided if the contract exceeds $50,000, and a Payment Bond is required if it exceeds $25,000.
Bidders must comply with all federal, state, county, and local laws applicable to construction projects.
Additionally, Jefferson County encourages participation from Disadvantaged Business Enterprises (DBEs), Minority/Women Business Enterprises (M/WBEs), and Historically Underutilized Businesses (HUBs).
The Jefferson County Purchasing Department is issuing an Invitation for Bids (IFB 26-021/MR) for roofing renovations at the Jefferson County Courthouse.
The purpose of this project is to enhance the structural integrity and aesthetic appeal of the courthouse, which serves as a vital facility for county operations.
The specifications for this project can be accessed through the Jefferson County website or by contacting The LaBiche Architectural Group, Inc.
Work Details
The contract involves comprehensive roofing renovations at the Jefferson County Courthouse.
Specific tasks include:
- Removal of existing roofing materials
- Installation of new roofing systems that meet current building codes and standards
- Ensuring proper insulation and waterproofing measures are implemented
- Compliance with all safety regulations during construction
- Provision of necessary documentation and warranties for materials used.
All work must adhere to the specifications outlined in the project manual provided by The LaBiche Architectural Group, Inc.
Period of Performance
The contract period will commence upon execution of the contract and is expected to be completed within a specified timeframe detailed in the bid documents.
The contractor must provide a schedule that outlines key milestones and completion dates.
Place of Performance
The work will be performed at the Jefferson County Courthouse located at 1149 Pearl Street, Beaumont, Texas 77701.
Bidder Requirements
Bidders are required to furnish a Bid Security amounting to five percent (5%) of the total contract cost.
A Performance Bond must be provided if the contract exceeds $50,000, and a Payment Bond is required if it exceeds $25,000.
Bidders must comply with all federal, state, county, and local laws applicable to construction projects.
Additionally, Jefferson County encourages participation from Disadvantaged Business Enterprises (DBEs), Minority/Women Business Enterprises (M/WBEs), and Historically Underutilized Businesses (HUBs).
Loading Map
Loading Map
Overview
Agency
Opportunity ID
IFB26021MR
Response Deadline
May 6, 2026
Due in 26 Days
Date Posted
March 31, 2026
Est. Value Range
Experimental
$500,000 - $2,000,000
(AI estimate)
Agency Distribution
High
Source
On 3/31/26 Jefferson County in Texas issued Roofing Renovations for Jefferson County Courthouse with ID IFB26021MR due 5/5/26.
Contacts
Documents
Posted documents for Roofing Renovations for Jefferson County Courthouse
Opportunity Assistant
Additional Details
Class Codes
91078-Weatherization, Weather And Waterproofing Maintenance And Repair Services;
91066-Roofing, Gutters, And Downspouts Maintenance And Repair;
77000-Roofing Materials And Supplies;
77093-Waterproofing Membrane And Base Sheet;