USNS JOHN LEWIS PSA   3

Background
The Military Sealift Command has a requirement for the upcoming Post Shakedown Availability (PSA) for the USNS JOHN LEWIS (T-AO 205). The contract will commence at the contractor’s facility on or about 01 September 2023 and will continue for an anticipated period of one hundred and sixty-five (165) calendar days.

Work Details
The contract work includes various tasks such as preparing for and accomplishing the VR, overhaul, or alterations of the USNS JOHN LEWIS (T-AO 205) as specified in the WI package provided in Attachment J-1. The contractor is responsible for providing necessary management, procurement, production, testing, technical capability and resources, and quality assurance services.

The work also involves using progress measurement systems to determine the physical progress of completed work, developing a performance milestone schedule/critical path chart, applying approved quality control procedures, ensuring configuration control procedures are maintained for procured material and production work, managing all subcontractors’ performance during the availability, employing good judgment and sound engineering practice and principles, and ensuring ship's equipment and systems remain configured to existing baselines with regard to procured material, production work, and software.

Period of Performance
The contract will be performed over an anticipated period of one hundred and sixty-five (165) calendar days starting on or about 01 September 2023.

Place of Performance
All work shall be performed at the contractor’s shipyard.