Search Contract Opportunities

7th Floor Clerk of the Court and Magistrate Chamber Expansion, San Diego, CA   4

ID: 47PK0123R0002 • Type: Solicitation

Description

Posted: Oct. 30, 2023, 8:19 p.m. EDT

This Solicitation is set-aside for Small Business Concerns, in accordance with FAR 19.

The U.S. General Services Administration (GSA) has a requirement to provide construction services involving approximately 14,790 square feet on a partially occupied floor on the 7th Floor at the James M. Carter and Judith N. Keep United States Courthouse in San Diego, CA. The tenant improvement includes construction of four (4) new magistrate chamber suites and Clerk of the Court office space on the 7th Floor of the Courthouse.

This project will involve: mechanical, electrical, plumbing, elevator programming, fire and life safety, data, audio and visual, and security systems; the highest quality interior finishes; and premium quality millwork. The work must be performed after hours with no disruption to the existing building tenants and operations.

Amendment No. 1 issued 4/19/2023

Amendment No. 2 issued 4/25/2023

Amendment No. 3 issued 5/12/2023

Posted: May 12, 2023, 7:21 p.m. EDT
Posted: April 25, 2023, 6:04 p.m. EDT
Posted: April 19, 2023, 9:26 p.m. EDT
Posted: March 27, 2023, 3:59 p.m. EDT
Background
The U.S. General Services Administration (GSA) has a requirement to provide construction services involving approximately 14,790 square feet on a partially occupied floor on the 7th Floor at the James M. Carter and Judith N. Keep United States Courthouse in San Diego, CA. The tenant improvement includes construction of four (4) new magistrate chamber suites and Clerk of the Court office space on the 7th Floor of the Courthouse.

Work Details
This project will involve: mechanical, electrical, plumbing, elevator programming, fire and life safety, data, audio and visual, and security systems; the highest quality interior finishes; and premium quality millwork. The work must be performed after hours with no disruption to the existing building tenants and operations.

Period of Performance
The Contractor shall commence performance of the Work within 10 days after receiving the Notice to Proceed (NTP). The Contractor shall achieve Substantial Completion of the Work no later than 335 calendar days from issuance of NTP. The Contractor shall achieve Contract Completion within 30 calendar days of Substantial Completion.

Place of Performance
James M. Carter and Judith N. Keep United States Courthouse, 333 W. Broadway, San Diego, CA 92101
Show All

Overview

Agency
PBS Region 9: Pacific Rim Region [GSA - PBS]
Response Deadline
May 22, 2023, 7:00 p.m. EDT (original: May 4, 2023, 7:00 p.m. EDT) Past Due
Posted
March 27, 2023, 3:59 p.m. EDT (updated: Oct. 30, 2023, 8:19 p.m. EDT)
Set Aside
Small Business (SBA)
NAICS
236220 - Commercial and Institutional Building Construction
PSC
Z2AA - Repair Or Alteration Of Office Buildings
Place of Performance
San Diego, CA 92101 United States
Source
SAM
Current SBA Size Standard
$45 Million
Pricing
Likely Fixed Price
Est. Level of Competition
Average
Signs of Shaping
55% of obligations for similar contracts within the Public Buildings Service were awarded full & open.
On 3/27/23 PBS Region 9: Pacific Rim Region issued Solicitation 47PK0123R0002 for 7th Floor Clerk of the Court and Magistrate Chamber Expansion, San Diego, CA due 5/22/23. The opportunity was issued with a Small Business (SBA) set aside with NAICS 236220 (SBA Size Standard $45 Million) and PSC Z2AA.
Primary Contact
Name
Dan Makowski   Profile
Email
dan.makowski@gsa.gov
Phone
(480) 479-2880

Documents

Posted documents for Solicitation 47PK0123R0002

Question & Answer

Opportunity Lifecycle

Procurement notices related to Solicitation 47PK0123R0002

Award Notifications

Agency published notification of awards for Solicitation 47PK0123R0002

Contract Awards

Prime contracts awarded through Solicitation 47PK0123R0002

Incumbent or Similar Awards

Contracts Similar to Solicitation 47PK0123R0002

Potential Bidders and Partners

Awardees that have won contracts similar to Solicitation 47PK0123R0002

Similar Active Opportunities

Open contract opportunities similar to Solicitation 47PK0123R0002

Additional Details

Source Agency Hierarchy
GENERAL SERVICES ADMINISTRATION > PUBLIC BUILDINGS SERVICE > PBS R9 ACQUISITION MANAGEMENT DIV
FPDS Organization Code
4740-KX000
Source Organization Code
100173640
Last Updated
Nov. 30, 2023
Last Updated By
dan.makowski@gsa.gov
Archive Date
Nov. 30, 2023